FIDIC Red Book Construction Contract
FIDIC Red Book Construction Contract Conditions of Contract for Construction FOR BUILDING AND ENGINEERING WORKS DESIGNED BY THE EMPLOYER First Edition, 1999. fidic red book fidic tendering procedure fidic green book fidic contracts pdf fidic latest edition fidic contracts fidic dredging contract fidic bookshop.
FIDIC Red Book Construction Contract
- General Conditions
- Guidance for the Preparation of the Particular Conditions
- Forms of Tender, Contract Agreement and Dispute Adjudication Agreement
Table of content FIDIC Red Book Construction Contract
1 GENERAL PROVISIONS
2 THE EMPLOYER
3 THE ENGINEER
4 THE CONTRACTOR
5 NOMINATED SUBCONTRACTORS
6 STAFF AND LABOUR
7 PLANT, MATERIALS AND WORKMANSHIP
8 COMMENCEMENT, DELAYS AND SUSPENSION
9 TESTS ON COMPLETION
10 EMPLOYER’S TAKING OVER
11 DEFECTS LIABILITY
12 MEASUREMENT AND EVALUATION
13 VARIATIONS AND ADJUSTMENTS
14 CONTRACT PRICE AND PAYMENT
15 DEFAULT OF CONTRACTOR
16 DEFAULT OF EMPLOYER
17 RISK AND RESPONSIBILITY
19 FORCE MAJEURE
20 CLAIMS, DISPUTES AND ARBITRATION
fidic red book, fidic tendering procedure, fidic green book, fidic contracts pdf, fidic latest edition, fidic contracts, fidic dredging contract, fidic bookshop
The FIDIC Red Book Construction Contract comprise the “General Conditions”, which form part of the “Conditions of Contract for Construction” First Edition 1999 published by the Fédération Internationale des Ingénieurs-Conseils (FIDIC), and the following “Particular Conditions”, which include amendments and additions to such General Conditions.
FIDIC Red Book Construction Contract which are recommended for building or engineering works designed by the Employer or by his representative, the Engineer. Under the usual arrangements for this type of contract, the Contractor constructs the works in accordance with a design provided by the Employer. However, the works may include some elements of Contractor-designed civil, mechanical, electrical and/or construction works. The forms are recommended for general use where tenders are invited on an international basis. Modifications may be required in some jurisdictions, particularly if the Conditions are to be used on domestic contracts. FIDIC considers the official and authentic texts to be the versions in the English language. fidic red book fidic tendering procedure fidic green book fidic contracts pdf fidic latest edition fidic contracts fidic dredging contract fidic bookshop.
In the preparation of these FIDIC Red Book Construction Contract for Construction, it was recognised that, while there are many sub-clauses which will be generally applicable, there are some sub-clauses which must necessarily vary to take account of the circumstances relevant
to the particular contract. The sub-clauses which were considered to be applicable to many (but not all) contracts have been included in the General Conditions, which will facilitate their incorporation into each contract.
The General Conditions and the Particular Conditions will together comprise the Conditions of Contract governing the rights and obligations of the parties. It will be necessary to prepare the Particular Conditions for each individual contract, and to take account of those sub-clauses in the General Conditions which mention the Particular Conditions.
ISBN : 2-88432-022-9
Number page : 120 pages
Download Type : PDF File, FIDIC Red Book Construction Contract
File Type Download : PDF File FIDIC Red Book Construction Contract
fidic conditions of contract for construction red book pdf free download, fidic conditions of contract red book for construction free download, fidic red book pdf
Download : FIDIC Red Book Construction Contract